--- name: rea-request title: Request for Equitable Adjustment (REA) description: Drafts a Request for Equitable Adjustment (REA) for U.S. federal government contracts under FAR provisions. Enforces element-driven cost/schedule narratives, FAR Part 31 cost structures, FAR 52.233-1 certification, and contemporaneous evidence marshaling. Use when a contractor seeks contract modification relief due to government-directed changes, differing site conditions, defective specifications, or government-caused delays. author: CaseMark author_url: https://github.com/CaseMark/skills/tree/main/skills/legal/rea-request license: Apache-2.0 version: 0.1.0 execution_mode: open jurisdiction: us practice: government-contracts language: en tags: [drafting, letter] --- # Request for Equitable Adjustment (REA) Drafts a litigation-ready REA asserting entitlement, quantifying cost and schedule impacts, and satisfying FAR certification requirements for submission to a federal contracting officer. ## Prerequisites 1. **Contract documents** — base contract, modifications, PIID, applicable FAR clauses (esp. FAR 52.243-1 or FAR 52.243-4) 2. **Change trigger documentation** — government directive, modification order, or differing-conditions notice with precise dates 3. **Cost records** — timesheets, invoices, purchase orders, subcontract documents, cost ledgers 4. **Schedule records** — baseline CPM schedule, updates, delay logs, milestone tracking 5. **Project correspondence** — CO letters, emails, meeting minutes, daily logs contemporaneous with the change 6. **Contractor identity** — legal entity name, CAGE code, authorized signatory with delegation of authority ## Output Structure ### 1. Header Block | Field | Content | |---|---| | Contract No. / PIID | [Number] | | Agency / Contracting Office | [Name] | | Contracting Officer | [Name, address, contact] | | Contractor | [Legal name, CAGE code] | | REA Reference No. | [Internal tracking number] | | Date | [Submission date] | | Subject | Request for Equitable Adjustment — [Contract No.] | ### 2. Introduction & Legal Basis - Cite entitlement clause (e.g., FAR 52.243-1 Changes—Fixed-Price; FAR 52.243-4 Changes; differing site conditions clause) - State nature of change/event in one paragraph - Assert contractor's position: change exceeds original scope or constitutes a compensable change ### 3. Factual Narrative (Chronological) - Present events with dates referencing affected CLINs, SOW sections, or spec provisions - Quote government directives verbatim where available - Side-by-side: original requirement vs. changed/additional work - For differing conditions: baseline assumptions (contract) vs. actual conditions encountered - Cite exhibit numbers for each referenced document ### 4. Impact Analysis #### Cost Impacts (FAR Part 31) | Cost Element | Basis | Amount | |---|---|---| | Direct Labor (category/hours) | Timesheets / rates | $ | | Materials | Invoices / quotes | $ | | Equipment | Rental records / rates | $ | | Subcontractor Costs | Subcontract docs | $ | | Overhead (rate × base) | Rate agreement / incurred | $ | | G&A (rate × base) | Rate agreement / incurred | $ | | Profit / Fee | Contract structure / FAR guidelines | $ | | **Total Requested Adjustment** | | **$** | #### Schedule Impacts - Demonstrate critical path effect using CPM or comparable methodology - Quantify delay days per milestone and overall completion date - Address acceleration costs if contractor maintained original schedule despite change #### Performance Impacts - Describe changes to technical specs, quality standards, or deliverables ### 5. Supporting Evidence Index - **Tab A** — Contractual documents (contract, mods, specs, SOW) - **Tab B** — Government communications (directives, emails, CO letters, meeting minutes) - **Tab C** — Project records (daily logs, progress reports, inspection records) - **Tab D** — Financial documentation (invoices, timesheets, POs, cost ledgers) - **Tab E** — Expert analysis (engineering reports, schedule analysis, cost studies) - **Tab F** — Legal authorities (ASBCA/CBCA decisions, COFC precedents, FAR citations) [VERIFY each citation before filing] ### 6. Requested Adjustment Summary | Component | Requested | |---|---| | Total Cost Adjustment | $ | | Time Extension (calendar days) | [N] days | | Revised Completion Date | [Date] | | Affected Milestones | [List] | ### 7. Certification (FAR 52.233-1) > *For claims exceeding $100,000, include verbatim FAR 52.233-1(b) certification language [VERIFY current text]:* > > "I certify that the claim is made in good faith; that the supporting data are accurate and complete to the best of my knowledge and belief; that the amount requested accurately reflects the contract adjustment for which the contractor believes the government is liable; and that I am duly authorized to certify the claim on behalf of the contractor." **Signature block**: Authorized representative name, title, date, contact — confirm signatory has documented delegation of authority. ## Guidelines - **Notice** — Confirm timely notice under applicable changes clause; address late-notice arguments preemptively - **Causation** — Every cost/schedule element must trace to a specific government act or condition; no unsubstantiated lump sums - **Scope limitation** — Changes must be within general contract scope (cardinal change doctrine bars out-of-scope recovery) - **Cost principles** — All costs must be allowable, allocable, and reasonable under FAR Part 31; flag potentially unallowable costs - **Certification threshold** — Claims >$100,000 require FAR 52.233-1 certification; false certification triggers False Claims Act exposure - **Preserve entitlement** — State full position even when negotiating; frame concessions as facilitation, not waiver - **Contemporaneous docs** — Boards and courts heavily favor records created at the time of change over after-the-fact reconstruction - **[VERIFY]** all board/court citations (ASBCA, CBCA, COFC) before submission; confirm they remain good law